';


Title 48 Part 3452 → Subpart 3452.2 → §3452.242-71

Title 48 → Chapter 34 → Subchapter H → Part 3452 → Subpart 3452.2 → §3452.242-71

Electronic Code of Federal Regulations e-CFR

Title 48 Part 3452 → Subpart 3452.2 → §3452.242-71

e-CFR data is current as of November 18, 2019

Title 48Chapter 34Subchapter HPart 3452Subpart 3452.2 → §3452.242-71


Title 48: Federal Acquisition Regulations System
PART 3452—SOLICITATION PROVISIONS AND CONTRACT CLAUSES
Subpart 3452.2—Text of Provisions and Clauses


3452.242-71   Notice to the Government of delays.

As prescribed in 3442.7002, insert the following clause in all solicitations and contracts other than purchase orders:

Notice to The Government Of Delays (MAR 2011)

The contractor shall notify the contracting officer of any actual or potential situation, including but not limited to labor disputes, that delays or threatens to delay the timely performance of work under this contract. The contractor shall immediately give written notice thereof, including all relevant information.

(End of clause)


© e-CFR 2019

FR | USC | CFR | eCFR